Welcome to Archline Studios, a premier interior design and architectural firm specializing in 3D floor plans, exterior models, and immersive interior designs. By accessing or using our website (www.archlinestudios.com) or any services provided by Archline Studios, you agree to be bound by the following Terms and Conditions. Please read them carefully before using our services.
1. Acceptance of Terms
By using our website and services, you acknowledge that you have read, understood, and agree to comply with these Terms and Conditions. If you do not agree with any part of these terms, you must refrain from using our website and services.
2. Services Offered
Archline Studios provides architectural and interior design services, including but not limited to:
- 3D floor plans
- Exterior architectural models
- Interior design concepts and visualizations
- Consulting and project management services
All services are subject to availability, and we reserve the right to modify or discontinue any service without prior notice.
3. Project Engagement
Upon initiating a project with Archline Studios, clients are required to:
- Provide detailed information and specifications for the project.
- Collaborate with our design team throughout the design process.
- Approve and sign off on final designs and visualizations before any construction or implementation.
Archline Studios will provide an estimated timeline and budget based on the project scope. Delays in client feedback, approvals, or changes to the project scope may affect the delivery timeline and cost.
4. Intellectual Property Rights
All designs, concepts, visualizations, and materials created by Archline Studios are the intellectual property of Archline Studios. Clients are granted a limited license to use these materials solely for the agreed-upon project.
- Clients may not reproduce, distribute, or resell any designs or materials provided by Archline Studios without express written consent.
- Archline Studios reserves the right to showcase completed projects in our portfolio and for promotional purposes unless otherwise agreed upon in writing.
5. Confidentiality
Archline Studios values the privacy and confidentiality of our clients. Any personal or project-related information provided to us will be treated as confidential and used only for the purposes of delivering our services. We will not disclose any confidential information to third parties unless required by law or agreed upon by the client.
6. Payment Terms
Archline Studios operates under the following payment terms unless otherwise specified in the project contract:
- A non-refundable deposit is required before work begins on any project.
- Payment milestones may be set depending on the scope and duration of the project.
- The final payment is due upon completion and delivery of the project, prior to the release of final design files or visualizations.
Failure to make payments as agreed may result in delays, suspension, or termination of services.
7. Revisions and Amendments
We offer a reasonable number of revisions during the design phase to ensure client satisfaction. However, excessive changes or requests that fall outside the original project scope may incur additional charges and extend project timelines. Clients will be informed of any additional costs or delays prior to implementing such changes.
8. Limitations of Liability
Archline Studios is committed to providing high-quality services, but we cannot guarantee specific outcomes or results. To the fullest extent permitted by law:
- Archline Studios is not responsible for any indirect, incidental, or consequential damages arising from the use of our services.
- We are not liable for any delays or issues caused by third-party contractors or suppliers.
- Clients are responsible for ensuring the accuracy and completeness of information provided to us during the project.
9. Termination of Services
Either party may terminate the project at any time by providing written notice. If a client terminates the project before completion, Archline Studios reserves the right to retain the deposit and charge for any work completed up to the termination date.
Archline Studios may terminate services without notice if the client fails to comply with these Terms and Conditions or engages in any unlawful or unethical behavior.
10. Governing Law
These Terms and Conditions are governed by the laws of [Dehradun, Uttarakhand, India]. Any disputes arising from the use of our website or services will be subject to the exclusive jurisdiction of the courts in [Dehradun, Uttarakhand, India].
11. Changes to Terms and Conditions
Archline Studios reserves the right to modify these Terms and Conditions at any time without prior notice. Any changes will be effective immediately upon posting to our website. It is your responsibility to review the Terms and Conditions periodically for updates.
By using Archline Studios’ services, you agree to these Terms and Conditions and acknowledge that they may be updated or changed periodically. Thank you for choosing Archline Studios for your interior design and architectural needs.
